Illinois State University
Request for Professional Services Qualifications (QBS): Bone Student Center Re-Roofing Project
Number of Unsuccessful, Responsive Respondents:
Consultant: Inspec, Chicago, IL
An estimated start date of 8/30/2011 through 8/30/2015
The University award process may be delayed up to thirty days as this award goes through a state approval process.
First published Thursday, May 19, 2011
Illinois State University is seeking statements of qualifications from architectural and engineering firms interested in providing design services for the re-roofing of the Bone Student Center. This work may encompass all or parts of the Student Center, Braden Auditorium and the Brown Ballroom. The full scope of work will not be established until schedules and construction costs are established. Work includes complete tear-off and replacement of the existing membrane roof. The estimated cost for this project is not anticipated to exceed $1,500,000.
Qualifications and supporting materials will be accepted at the address below until 2:00 PM, Wednesday June 8, 2011:
Illinois State University at Uptown Crossing
1220 Campus Box
100 South Fell Avenue, Suite D
Any firm or individual who wishes to submit their qualifications in response to this solicitation must comply with the vendor requirements listed below, submit the State Board of Elections (SBE) certificate of business entity registration, complete and submit the Contractor Certifications and Conflicts Form (attached), complete and submit the Contractors Disclosures and Conflicts of Interest form (attached), and complete and submit the Vendor/Contractor Use of Subcontractors Form (attached). If you do not submit the SBE certificate (if required), the completed Contractor Certifications and Conflicts Form, the Contractors Disclosures and Conflicts of Interest form, and the Vendor/Contractor Use of Subcontractors form your qualifications may not be accepted by the University.
Your statement of qualifications must include the information requested above, the information included on the CDB 255 form, and any other information about your firm that you would like to include pertaining to this project. A copy of your CDB pre-qualification confirming your registration, the (1) Certificate of Business Entity Registration from the State Board of Elections, a copy of your (2) Contractor Certifications and Conflicts Form, (3) Contractors Disclosures and Conflicts of Interest form, (4) Vendor/Contractor Use of Subcontractors form, must be included in your response. Three copies of your statement of qualifications must be sent to Robyn Schuline, 1220 Purchasing Office, Uptown Crossing, 100 South Fell Avenue, Suite D, Normal IL 61761. Statements of Qualifications are due June 8, 2011, at 2:00 PM local time.
For additional information, contact:
Only those firms which meet the following qualifications will be considered:
- Submitted 3 copies of their qualifications.
- Licensed to practice as an architect, landscape architect, or engineer in the State of Illinois.
- Pre-qualified with the State of Illinois Capital Development Board.
- Registered and authorized to do business in the State of Illinois.
Selection will be consistent with the Architectural, Engineering, and Land Surveying Qualifications Based Selection Act (30 ILCS 535/1).
This transaction is subject to the State Board of Elections registration and certification requirements of Public Act 095-0971.
The State of Illinois has a policy to encourage prospective vendors to hire
qualified veterans, minorities, females, persons with disabilities and ex-offenders.